Aluminum for Signs
DLP Aluminum,
Contact and place of performance
Wesley Newell
MD 21502
USA
SV0206-26 Aluminum for Signs TERMS OF DELIVERY ARE F.O.B. DESTINATION TO: UNICOR, Federal Prison Industries, Inc. 14601 BURBRIDGE ROAD SE CUMBERLAND, MD 21502 Solicitation is issued as a two (2) year firm fixed price indefinite delivery-indefinite quantity type contract with Economic Price Adjustment for PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing. Offerors who do not agree with the Producer Price I...
View moreFor a list, description and total estimated quantities of all items, refer to Section B.
UNICOR’s desired delivery is 21 calendar days or sooner from receipt of each delivery order issued. Vendors are required to provide their best manufacturing/delivery time for evaluation which will be evaluated under technical factors as a go/no go. Delivery schedule will be established at time of award. Delivery orders will be issued in accordance with 52.216-19.
Vendors shall submit signed and dated offers by email to: [email protected]
OMB Clearance 1103-0018.
SAM.gov Solicitation Posting: 3/27/2026
Questions Deadline: 4/3/2026 8AM EST
Proposal Deadline: 4/17/2026 2PM EST
Offer must indicate Solicitation No. SV0206-26, time specified for receipt of offer, name, address and telephone number of Offeror, technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation, terms of any expressed warranty, price and any discount terms. Offer must include acknowledgment of all amendments, if any.
THE FOLLOWING INFORMATION IS REQUIRED TO BE COMPLETED BY THE OFFEROR:
SAM UNIQUE ENTITY NUMBER:_______________________________________
VENDOR'S POINT OF CONTACT: _____________________________________
VENDOR'S TELEPHONE NUMBER: _____________________________
VENDOR'S EMAIL ADDRESS: ________________________________________
VENDOR'S BUSINESS SIZE (i.e. SMALL, LARGE, ETC.): __________________
By submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.
_______________________________________________ Signature
The Administrative Contracting officer is Wesley Newell at [email protected].
SECTION B:
Unicor is looking to create a contract for the following items to make Digital License Plates:
Line 1 SBL0127A ALUM-BLANK,10INX7IN,.040-THK,CAUTION* 50,000 EA
ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR
Line 2 SBL0133 ALUM,BLNK,.032"X4-1/2"X5",YELLOW 20,000 EA
ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR
Line 3 SBL0128 .032"X2-1/2"X15",RECTANGLE,ALUMINUM, 1,000 EA
ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR
PART I: INFORMATION
This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number is SV0206-26 and this solicitation is issued as a Request For Quote (RFQ). The North American Industry Classification System code is 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400). This requirement is 100% set-aside for small business; small business size standard for this solicitation is 1,400 employees. UNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):
SEE SECTION B FOR LIST OF ITEMS
Guaranteed contract minimum is 40,000 FT.
Minimum delivery order is 4,000 ft or $10,520.
Maximum delivery order is 10,000 ft or $26,300.
A Single Award or a Multiple Award may be made.
Contracting Officer’s Representative (COR) will be Michael Southern. Factory Manager, Unicor Cumberland Sign Factory, 301-784-1000.
Any contract resulting from this solicitation will not be an obligation. Funds will be obligated by delivery orders.
NOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
In the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
Contractor agrees that FPI is in the category of the most favored or best commercial customer category of the Contractor and as such, the Contractor will:
During the contract period, the Contractor shall report to the Contracting Officer all price reductions offered to the category of customers that are considered by the Contractor to be their most favored or best commercial customer.
1. A price reduction shall apply to purchases under this contract if, after the award date, the Contractor-
i) Revises downward its commercial catalog, price list, schedule, etc., to its best commercial customers (or category of customers) below the awarded price under this contract;
ii) Grants more favorable discounts or terms and conditions to its best commercial customers than those contained in this contract that would result in prices below the awarded price under this contract, an/or
iii) Grants special discounts to its best commercial customer (or category of
customers) that would result in prices lower than the awarded price under this contract.
2. The Contractor shall offer the price reduction to FPI with the same effective date, and for the same time period, as extended to the commercial customer (or category of customers).
The Contractor may offer the Contracting Officer a voluntary price reduction at any time during the contract period.
The Contractor shall notify the Contracting Officer of any price reduction subject to this clause as soon as possible, but not later than 15 calendar days after its effective date.
Future requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.
Packaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.
INVOICES ARE TO BE EMAILED TO:
Federal Prison Industries, Inc. (UNICOR) is soliciting quotes for aluminum blanks and sheets to support the production of digital license plates at its facility in Cumberland, Maryland. This requirement, issued under solicitation number SV0206-26, involves the delivery of various aluminum components including .040-thickness caution blanks, .032-thickness yellow blanks, and .032-thickness rectangular strips. The procurement is classified under NAICS 331315 Aluminum Sheet, Plate, and Foil Manufacturing and PSC 9515 PLATE, SHEET, STRIP, FOIL, AND LEAF. This opportunity is 100% set-aside for Small Business Administration (SBA) participants.
The agency intends to award a two-year firm-fixed-price indefinite delivery-indefinite quantity contract that includes an economic price adjustment based on the producer price index for aluminum sheet, plate, and foil manufacturing. The contract carries a guaranteed minimum of 40,000 feet, with individual delivery orders ranging from a minimum of 4,000 feet to a maximum of 10,000 feet. UNICOR requests a delivery turnaround of 21 calendar days or sooner from the receipt of each order, and vendors must provide their best manufacturing and delivery times for technical evaluation. All deliveries are to be made F.O.B. destination to the UNICOR Cumberland Sign Factory.
Responses are due by April 17, 2026, and any questions regarding the solicitation must be submitted in writing by April 3, 2026. Submissions must be emailed to Wesley Newell and include technical descriptions, pricing, and a completed business management questionnaire. The solicitation notice is supported by four attachments, including updated specifications, the original solicitation document from March 27, 2026, and a questionnaire for offerors. Future requirements for similar items may be added to the resulting contract if they fall within the scope of work and meet fair and reasonable pricing standards.
Generated by Lumen AI
Scoped analysis and attachments—go beyond the summary when you need detail from the solicitation package.